Arbitration and Award Templates
Petition For Appointment Of A Sole Arbitrator Arbitration & Award 1200
Category: Arbitration And Award
PETITION FOR APPOINTMENT OF A SOLE ARBITRATOR petitioner respondent court agreement arbitrator PETITION FOR APPOINTMENT OF A SOLE ARBITRATOR In the High Court at Calcutta Ordinary Original Civil Jurisdiction In the matter of The Arbitration Conciliation Act 1996 And In the matter of An application under section 11 of the said Act And In the matter of An Arbitration Agreement contained In the Contract No 3 dated And In the matter of Builders India Private Ltd a company registered under the Companies Act 1956 and carrying on business at 7A Camac Street Calcutta 700 016 Petitioner versus S N Udyog Private Ltd a company registered under the Companies Act 1956 and carrying on business at 6 S P Mukherjee Road Calcutta 700 025 Respondent To TheHon bleMr Chief Justice and His Companion Justices of the said Hon ble Court The humble petition of the petitioner above named most respectfully Sheweth 1 Your petitioner is engaged in construction business...
Arbitration Clause In A Partnership Agreement Arbitration & Award 1186
Category: Arbitration And Award
Arbitration Clause in a Partnership Agreement partner arbitration partnership thereof dispute Arbitration Clause in a Partnership Agreement All disputes and questions whatsoever which shall arise during the partnership or afterward between the partners or their respective legal representatives or between any partners or partner and the legal representative of any other or others deceased partner or partners touching this Deed or the construction or application thereof or any clause or thing herein contained or any account valuation or division of assets debts or liabilities to be made hereunder or as to any act deed or other omission of any partner or as to any other matter In any way relating to the partnership matters or the effect thereof or the rights duties or liabilities of any person hereunder shall be referred to the Arbitration of Arbitrators one to be appointed by each party to the dispute or questions and the Arbitration shall be governed by the provision...
Arbitration Clause Where The Arbitrator Is To Be Nominated By A Third Person Arbitration & Award 1188
Category: Arbitration And Award
Arbitration Clause where the Arbitrator is to be nominated by a third Person arbitration arbitrator nominate party connection Arbitration Clause where the Arbitrator is to be nominated by a third Person All disputes or questions arising out of or in connection with this agreement between the parties shall be referred to the sole arbitration of an Arbitrator to be nominated by the destination of the person or officer within fifteen days from the receipt of the application by any party to Association or Government Department of failing which to the arbitration of one or more arbitrators to be nominated by the Chief Justice of the High Court of as per the provisions of the Arbitration and Conciliation Act 1996...
Notice Under Section 11 Of The Arbitration And Conciliation Act 1996 Arbitration & Award 1199
Category: Arbitration And Award
Notice under section 11 of the Arbitration and Conciliation Act 1996 To Builders India Private Ltd 7A Camac Street Calcutta 700 016 Dear Sirs Re Arbitration of the disputes arising out of Contract No 3 entered with us You had entered into a Contract No 3 with us undertaking to construct certain flats and guest houses on terms and conditions contained in said contract You have failed to complete construction and to make over delivery of possession of houses you had agreed to construct on our behalf We have paid you advances and also all your running bills In spite of this you are inordinately delaying the matter Time was of the essence of the contract You have failed to keep the time schedule The few apartments and guest houses that you have constructed and agreed for joint inspection were found to be defective and not suitable for occupation of the staff and they have not yet been made habitable In spite of requests you have failed and neglected to complete the work As...
Agreement For Reference To Arbitration Between The Executor And Legatees Arbitration & Award 1175
Category: Arbitration And Award
AGREEMENT FOR REFERENCE TO ARBITRATION BETWEEN THE EXECUTOR AND LEGATEES legatee executor arbitrator party testator AGREEMENT FOR REFERENCE TO ARBITRATION BETWEEN THE EXECUTOR AND LEGATEES Agreement made at this day of between Mr hereinafter referred to as the Executor and 1 2 3 hereinafter referred to as the Legatees of the other part WHEREAS 1 One M died at on the day of leaving behind him his last Will and testament dated 2 By the said Will the said testator appointed Mr as a sole executor of the said Will 3 The Executor has proved the Will and obtained probate thereof from the High Court at on the day of By the said Will the testator has made some bequests and has bequeathed his residency estate to the Legatees Disputes and differences have arisen between the Executor and Legatees regarding the true meaning of certain provisions of the Will and as to the several interests of the Legat...
Arbitration Clause In Common Form Arbitration & Award 1187
Category: Arbitration And Award
Arbitration Clause in Common form party dispute arbitration difference arbitrator Arbitration Clause in Common form All the disputes and differences arising between the parties hereto including any dispute or difference in regard to the interpretation of any provision or term or the meaning thereof or in regard to any claim of one party against the other or in regard to the rights and for obligations of any party or parties hereto under this Agreement or otherwise howsoever shall be referred to a common Arbitrator if agreed upon by all or otherwise to two Arbitrators one to be appointed by each party to the dispute or difference and such Arbitration shall be governed by the provisions of the Arbitration Act for the time being in force...
Petition Praying For Interim Measures Arbitration & Award 1204
Category: Arbitration And Award
PETITION PRAYING FOR INTERIM MEASURES petitioner respondent bank guarantee term PETITION PRAYING FOR INTERIM MEASURES In the High Court at Calcutta Ordinary Original Civil Jurisdiction In the matter of The Arbitration Conciliation Act 1996 And In the matter of An application under section 9 of the said Act And In the matter of An Arbitration Agreement contained In the Contract No 3 dated And In the matter of Builders India Private Ltd a company registered under the Companies Act 1956 and carrying on business at 7A Camac Street Calcutta 700 016 Petitioner versus S N Udyog Private Ltd a company registered under the Companies Act 1956 and carrying on business at 6 S P Mukherjee Road Calcutta 700 025 Respondent To The Hon ble Mr Chief Justice and His Companion Justices of the said Hon ble Court The humble petition of the petitioner above named most respectfully Sheweth 1 The petitioner is engaged in construction of houses flats guest houses and o...
Notice Under Arbitration And Conciliation Act 1996 Arbitration & Award 1198
Category: Arbitration And Award
Notice under Arbitration and Conciliation Act 1996 lease client r th rental Notice under Arbitration and Conciliation Act 1996 By Speed Post with A ID Date Dhillon Industrial Corporation Ltd 15 1 A J R Nagar Bangalore 560 078 Dear Sirs Client Smart Finance Co Ltd of Calcutta Re Lease in respect of computer machinery Under instructions from and on behalf of my client Smart Finance Co Ltd I address you as follows You entered into a Lease Agreement dated 5th December 1999 with our client above named in respect of machinery referred to above and agreed inter alia to pay to them monthly Lease Rent of Rs 50 000 commencing from 5th January 2000 The tenure of the said Lease was for 3 years from the date of commencement You have failed and neglected to perform your part of the obligation defaulted in payment of the lease rentals and in furnishing the Security Deposit You have therefore committed breaches of the Agreement and defaults in payment and are liable t...
Petition For Substitution Of Arbitrator Upon Termination Of Mandate Arbitration & Award 1203
Category: Arbitration And Award
Petition for Substitution of Arbitrator upon Termination of Mandate petitioner arbitrator calcutta court matter Petition for Substitution of Arbitrator upon Termination of Mandate In the High Court at Calcutta Ordinary Original Civil Jurisdiction In the matter of The Arbitration Conciliation Act 1996 And In the matter of An application under section 15 of the said Act And In the matter of An Arbitration Agreement contained in the Contract No 3 dated And In the matter of Builders India Private Ltd a company registered under the Companies Act 1956 and carrying on business at 7A Camac Street Calcutta 700 016 Petitioner versus 1 S N Udyog Private Ltd a company registered under the Companies Act 1956 and carrying on business at 6 S P Mukherjee Road Calcutta 700 025 2 Mr Somnath Banerjee of 7 Hindustan Park Calcutta 700 029 Respondents To The Hon ble Mr Chief Justice and His Companion Justices of the said Hon ble Court The humble petition of t...
Award Made Under An Order Of The Court Arbitration & Award 1196
Category: Arbitration And Award
AWARD MADE UNDER AN ORDER OF THE COURT etc award matter court arbitrator AWARD MADE UNDER AN ORDER OF THE COURT This is the award of the Arbitrator made this day of 2005 Whereas in pursuance of an order of reference dated the day of made by the court in Suit No of 2005 of the court of etc the following matters in difference between the above named AB and CD namely etc state the matter in difference were referred to us for arbitration and determination Now we the undersigned having heard and examined the parties and considered all allegations and counter allegations and submissions made against each other and all documents and other evidences produced and laid before us made our award as follows We award 1 that etc 2 that etc Date Arbitrator...
- ‹ Prev
- 1
- 2
- 4
- Next ›
- Last »