Ans Constructions Pvt Ltd vs.ramagundma Fertilizer & Chemicals Ltd & Ors.

Decided On : May-24-2019

Court : Delhi

LAW: Section 9, Analysis 9, Page 10, Page 11

MONEY: ~15, Fifty One Thousand

ORG: ANS CONSTRUCTIONS PVT LTD, FERTILIZER & CHEMICALS LTD & ORS, Bank Guarantee, Respondent No.3, Canara Bank, National Fertilisers Ltd., NFL, Engineers India Ltd., EIL, Fertilisers Corporation of India, FCI, Gas, Urea, Engineering Consultancy Services, EPC, Bank, Bank Guarantee, Ramagundam Fertilizer Complex, 3rd September 2016, Performance Bank Guarantee Nos, the General Conditions of Contract, GCC, the Contract Price, the Contract Performance Bank Guarantee, Bank Guarantee, Bank Guarantee, Hindrance Delay, 03.10.2016, RRM, CPP Non, Bitumen Rains 04.01.2016, the Bank Guarantees, the Performance Bank Guarantee, the Bank Guarantee, Bank Guarantee, Court, the Bank Guarantee, Performance Bank Guarantee, the Bank Guarantee, the Bank Guarantee, Court, Hindustan Construction Co. Ltd., CMD, DRB, Reliance, State Trading Corporation of, State Bank of India, See Synthetic Foams Ltd., Hindustan Construction Co. Ltd. & Anr, Satluj Jal Nigam Ltd., Dwarikesh Sugar Industries, the Swiss Court, GAFTA, Bank Guarantee, the Bank Guarantee, General Conditions of Contract, GCC, GCC, RA, BG, the Bank Guarantee, the Bank Guarantee, E2/B1 Exten, Industrial Estate, Mathura Road New Delhi-110044, Site Grading, Road, Drain for Revival of Ramagundam Fertilizer Complex, Price Reduction Guarantee, Guarantor, the Bank Guarantee, Contract, Price Reduction Guarantee, Taxes, the Price Reduction, Guarantor, Price Reduction Guarantee, Contract, Price Reduction Guarantee, Price Reduction Guarantee, Price Reduction Guarantee, Price Reduction Guarantee, Contract, Contract, Guarantor, Price Reduction Guarantee, Price Reduction Guarantee, Contract, the Bank Guarantee, the Bank Guarantee, Bank Guarantee, Ramagundam Fertilizers and, Chemicals Limited, Bank Guarantee, Bank Guarantee, Bank, Bank Guarantee, The Supreme Court, U.P. State Sugar Corporation, Sumac International Ltd., Himadri Chemicals Industries Ltd., Coal Tar Refining Company AIR2007SC2798 BSES Ltd., Fenner India Ltd., Bank, the Bank Guarantee, the Bank Guarantee, the Bank Guarantee, the Apex Court, the Bank Guarantee, Bank, Court, Bank Guarantee, Bank, Bank, the Supreme Court, BSES Ltd., Fenner India Ltd, U.P. State Sugar Corporation, Sumac International Ltd., State, Maharashtra v. National Construction Co., United Commercial Bank, Bank of India, Vinmar Impex Inc., U.P. State Sugar Corporation, Sumac International Ltd., U.P. State Sugar Corporation, Court, Bank Guarantee, the Supreme Court, U.P. State Sugar Corporation, Sumac International Ltd., Fab-Tech Works & Constructions Pvt. Ltd., Court, Bank Guarantee, the Supreme Court of India.10, The Supreme Court, U.P. Coop, Federation Ltd., Singh Consultants and Engineers, Bank Guarantee, Bank Guarantees, The Supreme Court, The Supreme Court, U.P. State, Sumac International Ltd., Bank Guarantee, Bank Guarantee, Bank Guarantee, Bank Guarantee, Bank Guarantee, Bank Guarantee, Bank Guarantee, Bank Guarantee, The Supreme Court, U.P. State, the Supreme Court, U.P. State, Bank Guarantees, the Bank Guarantee, Court, Court, Court, The Bank Guarantee, the Bank Guarantee, The Bank Guarantee, Court, the Bank Guarantee, Court, Court

PERSON: Sandeep Aggarwal, Sushil Aggarwal, Vasundhra Nayyar, Delay, Delay, Satluj Jal Vidyut Nigam Ltd., Simplex Concrete Piles, Mohan Cooperative, Contractor, Contractor, Contractor, Applicable Law, Contractor, Contractor, Contractor, Contractor, Contractor, Contractor, Contract, Contractor, MANU, Sujata V. Manohar, facie, Sugar Corpn, Sugar Corpn, Sugar Corpn

GPE: I.A., Telengana, Demonetization, Delhi, O.M.P.(I, Bombay

DATE: 7774/2019, 1996, 4th January 2016, a period of, 8 months, 27th January 2016, 30th September 2017, 55, 28th February 2019, 27th November 2018.6, days, 11.02.2016 10.02.2016, 04.01.2016 10.02.2016, 11.02.2016, 80 80, 33 33, 09.11.2016 31.01.2017, 300 84 7, January 2018, 18th March 2019, 22nd March 2019, 25th March 2019, 27th March 2019, 18th March 2019, 22nd March 2019, 22nd May 2019, 7th July, 2003, July 2004, 20.09.2003, 19 11, 2013, 2007, five) days, 2015, 1988, interfere.11, 1997

CARDINAL: 1, 2, 1, 2, 1,73,25,810/-, 1, 19, 3, 1, No.3, one, 13.2.1, 156/2019, 2, 19, 38, 38, 79, 3, 189, 159, 22, 300, 84, 4, 19, 2,20,51,644/-, 5, 19, 25, 6, 19, 7, 200, 19, 169, 12, 55, 8, 19, 13, 2,20,51,644/-, Two, Twenty, 14, 1, 9, 19 2, 5, 31.08.2017, 19, 19, 15, 12, 19, 16, only two, 13, 19, 10, two, 1981].3SCR300, 14, 19, 18, two, 19, 224, 9, 1, 15, 19, 1, only two, 16, 19, 20, two, 17, 19, 18, 19, 19, 19

LOC: Ramagundam, Respondent, Respondent, Respondent

FAC: Joint Venture

PERCENT: 1%, 10%

WORK_OF_ART: Date Start of Hindrance of Date, Site Enabling Works, 04.01.2016, Price Reduction

ORDINAL: 9th, first, second, second, second, second

PRODUCT: Respondent No.2, Respondent, Respondent.10, Guarantor, Respondent