Sunborne Energy Rajasthan Solar Pvt. Ltd vs.ntpc Vidyut Vyapar Nigam Ltd

Decided On : Apr-15-2019

Court : Delhi

LAW: Section 34, Article 1.1 of the PPA, Section 9, the Arbitration Agreement, the Impugned Award, a Transmission Agreement, Article 3.1, Article 15, Article 4.1, Article 4.5.2, Article 16, Article 4.6.3, Article 3.1, Section 34, Article 4 of the PPA, Article 4.1.1, Article 3.1,the, Article 3.2, Article 11 of the PPA, Article 11.4.1(f)(i, Article 4.6, Article 4.6.1, Article 3.1, Article 3.1, Article 3.1.29, Niyam 9, Article 11.4.1 f, Article 11.4.1 e, Article 4.5 of the Power Purchase Agreement, Article 11.5, Article 11.5 of the PPA, Article 11.5 of the PPA, Article 11.5, the Force Majeure Clause, Article 3.1 and 4.1.1, Article, Article 3.1, Article 3.1, Article 3.2, Article 3.1, Article 4.5, Article 4.5.1, Article 13, Article 9.2 of this Agreement, Article 4, Article 9.2 of the PPA, Article 4.6.1 of the PPA, Article 9.2

CARDINAL: 11.2018, 15, 04.2019, 27.10.2015, 1, 24.08.2011, 25, 28.12.2011,in, 5MW, three, one, 27.01.2012.8, 5MW, 26.02.2013, 26.03.2013, 26.02.2013, 26.03.2013, 2, 04.04.2013, 11.04.2013, 22.01.2014, 11.04.2013, 2:1, One, 16.12.2016, 23.01.2012, 3 2,62,27,000, 23.11.2016, 200, 83, 18.06.2012, 22/23.05.2012, 24.08.2012, 78, 122, 200, one, 121, 07, 14.02.2013, 2.1, 2, 6, one, 4.5.4, 11.3, 8, 11.4, 11.5, 11.5.2, 26.03.2013, 24.08.2012, 11, three, 12, 26.02.2013, 13, 24.08.2012, 14, 24, 200, 16.01.2012, 23-24, 136, 83, 83, three, three, about 83, 200, 15, 200, about 122, approximately 100, 21, 07, 174, 11, 1were, about 83, 11.02.2013, 28, 83, 200, 11.02.2013, 200, 32, 83.14, 116, three, three, one, 120, 18.06.2012, 17, 18.06.2012, 35, 41, five, 34, 153, 154, 20.11.2012, 08.10.2012, 20.11.2012, three, 20.11.2012, 156, 19, one, 39, 37, 38, 41, 20, only 78, 200, 27, 15, 21, one, 200, 200, 11.02.2013, 47, 5, 29A, 29A, 22, 31, 24, 23, 34, at least seven, one, 3.3, 3.3.3, 25, one, more than one, more than two, 4.6.2, three, 4.6.3, eighteen, 4.6.4, 9, 26, 9.1, 9.3, 37, 28, 29

ORG: SUNBORNE ENERGY RAJASTHAN SOLAR PVT, Advs, Advs, JUSTICE NAVIN CHAWLA1, Arbitral Tribunal, the Bank Guarantee for Rs.2,62,27,000.00, the Power Purchase Agreement, The Government of India, the Jawaharlal Nehru National Solar Mission, OMP, the Ministry of Power, Government of India.4, LOI, Performance Bank Guarantees, Performance Bank Guarantee, the Scheduled Commissioning Date, the Bank Guarantees OMP, Court, Court, the Bank Guarantee, Court, the Arbitral Tribunal, Arbitral Tribunal, Arbitrators, Bank Guarantee, the Bank Guarantee, OMP, HSBC Bank, Court, Bank Guarantee, Project, Agricultural, Project, Agricultural, Project, Project, Project, OMP, the EXIM Bank, the State Bank of Patiala, Sunborne Energy Jaipur Solar, P) Ltd., Project, M/s, Sunborne Energy Jaipur Solar, P) Ltd., the Effective Date, SPD, the Effective Date, NVVN, OMP, Project Financing Arrangements, Consents, Clearances and Permits, NVVN, NVVN, Power Project, the Interconnection Facilities, STU, STU, SPD, SPD, JNNSM, NVVN, the Conditions Subsequent, the Effective Date, THE PROJECT ARTICLE4 CONSTRUCTION & DEVELOPMENT, SPD, Consents, Clearances and Permits, Consents, Clearances and Permits, the Power Project, the Contracted Capacity, NVVN, the Scheduled Commissioning Date, Agreement, Power Project, the Interconnection Facilities, the Power Project, Operation Date, xxxxxxx 4.5 Extensions of Time 4.5.1, SPD, the Scheduled Commissioning Date, NVVN Event of Default, NVVN, the Scheduled Commissioning Date, OMP, SPD, NVVN, the Force Majeure Events, SPD, NVVN, Event of Default, NVVN, the Scheduled Commissioning Date, the Expiry Date, Party, Dispute, the Scheduled Commissioning Date, the Expiry Date, the Scheduled Commissioning Date, the Expiry Date, the Scheduled Commissioning Date, Date, an Affected Party, the Affected Party, the Affected Party, OMP, the Power Project, the Affected Party, the Affected Party, Force Majeure, NVVN-Discom PSA, SPD, Discom, the Power Project, the Affected Party, The Affected Party, Party, Force Majeure, Party, Force Majeure, Force Majeure, OMP, Party, Force Majeure, Party, The Affected Party, Party, Party, the Force Majeure Event, The Affected Party, Party of (, Force Majeure, Force Majeure, Agricultural, non-Agricultural, Project, Project, the Bank Guarantee, OMP, the State Government, Force Majeure, Force Majeure, Clause, OMP, Project, the Scheduled Commissioning Date, Liquidated Damages, Performance Bank Guarantee, Bank Guarantee, Liquidated Damages, Project, Arbitral Tribunal, OMP, Project, the Arbitral Tribunal, Project Land, Tribunal, the Arbitral Tribunal, OMP, Project, Consents, Clearances and Permits, Project, Adhisoochna, SOC, the 'Prescribed Authority, SOC, SDO, SDO, Project, NA, Force Majeure, Prodent Utility Services, Solar Power i. Project, The Prescribed Authority, the Prescribed Authority, Solar Power Project, Claimant, OMP, Project Land, Power Project, SOC, P11or Ext, the Project Site, Tehsildar, OMP, Tehsildar, Pradhan, Moosa Ram, Tehsildar, R.I. Sahib Bap, Patwaris, OMP, Patwaris, Shiv Ram Meghwal, Project, OMP, Project, Financial Review, EPC, Erection, Procurement and Commissioning, Project, Project, Bank Guarantee, Project, Project, Conditions Subsequent, the Prescribed Authority, the Scheduled Commissioning Date, Force Majeure, the Affected Party's, SOC, Claimant, Claimant, Claimant, Claimant, OMP, the Arbitral Tribunal, Tribunal, NTPC Vidvut Vyapar Nigam Ltd., Court, Solar Power Developer, the Scheduled Commissioning Date, NVVN, Court, Pasithea Infrastructure Ltd., Solar Energy Corporation of India & Anr, Court, RFS, OMP, Frustration/Force Majeure, the Government Departments, The Arbitral Tribunal, the Bank Guarantee, the Clauses of the PPA, NVVN, NVVN, Bank Guarantees, SPD, OMP, SPD, the Conditions Subsequent, the Scheduled Commissioning Date, Performance Bank Guarantee, Contracted Capacity, SPD, the Scheduled Commissioning Date, NVVN, the Performance Bank Guarantee, NVVN, 4.6 Liquidated Damages, SPD, NVVN, the Scheduled Commissioning Date, NVVN, Liquidated Damages, Contracted Capacity, the Scheduled Commissioning Date, OMP, a. Delay, NVVN, Performance Bank Guarantee, NVVN, Performance Bank Guarantee, NVVN, Performance Bank Guarantee, Power Project, NVVN, the Liquidated Damages, MW, NVVN, Project Capacity, Performance Bank Guarantee, Liquidated Damages, the Effective Date, the Power Project, the Effective Date, Contracted Capacity, the Project Capacity Commissioned, the Effective Date, the Scheduled Date of Commissioning, OMP, CERC Applicable Tariff, CERC Applicable Tariff, the Commissioning Date of the balance Unit(s, the Weighted Average Tariff, Capacity of Units Scheduled Commissioning Date, Weighted Average Tariff, Discom, Performance Bank Guarantee, OMP, Equitable Sustainable Growth Model for India’s, Energy Estimate, Agreement, Discoms, the Arbitral Tribunal, OMP, RN OMP

PERSON: Tarun Johri, Ankur Gupta, Ankit Saini, Bharat Sangal, Babita Kushwaha, Award, JNNSM, JNNSM, Rajasthan, OMP3382013, Rajasthan, 3.1 Satisfaction, xxxxxxx 4, Law, b. Delay, c. Non-performance, d. Strikes, delay.23, Award, Ann, Rajasthan Bhu Rajasva, Gramin Kshetron, prayojan ke liye samparivartan, Niyam, Ann, CW1 Sri Gagan Vermani, Ann, P8(Vol, Ann, Khasra, Item Nos.10, Khasra, Ann, Square Meter, Rs.2,21,768.00, Rs.2,33,908.00, Rs.2,21,768.00, Sri Gagan Vermani, Ann, P11is, Patwari.(see, AGM Sri P.K. Gupta, Ann, Tehsildars, Shiv Lal, partwris, Tehsil Bap, Sarpanch Gram Panchayat, Gram Sewak, Momla Ram, CW1Sri Gagan Vermani, Gadhna, Gadhna, Claimant, No.8a, Award, Precision Technik Pvt, Schedule I., b. Delay, c. Delay, JNNSM

DATE: 1996, 27.01.2012, 23.01.2012, one month, 23.01.2012.11, one month, June 2012, 23.08.2012, October 2012, 4 17, 14.11.2012, January 2013, 27th January 2012, 210 days, 210 days, 1) year, less than „day, 30) days, March 31, 2013, 7) days, 9 19, 1) day, monthly, February, 2013, 31.03.2013, 23.08.2012, 210 days, one month, 25 years, 210 days, the month of October, 2012, four months, 59 to 83, 2007, 22.05.2012, next day, 172174, 11.02.2013, 16 30, 18.06.2012, 17.05.2012, only six days, one month later, 57 days, 19.02.2013, about 3 weeks, as late as 14.11.2012, about 8 weeks, 27.01.2012, 23.08.2012, 24.08.2012, 23.08.2012, 46, 2018, Del 13102, 2017, Del 12562, 7) days, the 7th day, 24 3.2.3, 1) month, 1) month, two months, three months, 3) months, 18) months, eighteen, 18) months, 18 months, 18 months, 27 38, 2019

GPE: India, Jodhpur, District Jodhpur, the Term of OMP, India, Rajasthan, Jodhpur, P.S., Rs.1,00,000/-, India

LOC: Respondent, Central Govt

PERCENT: 20%, 20%, 20%, 40%

QUANTITY: about 1 kilometre

FAC: the Delivery Point, the Delivery Point, the SPD g, Notice

PRODUCT: Agreement, Agreement, Agreement, Agreement, the Collector of the District, P-11, Agreement, Agreement, Agreement

EVENT: the Grid Code

ORDINAL: second, firstly, third, fourth

NORP: Indian, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, Patwari, NVVN46.1

WORK_OF_ART: 'Memorandum of Entry, Scheduled Caste/Scheduled Tribe, 44, this Agreement……, 3.2 Consequences of non-fulfilment of conditions subsequent 3.2.1, Commissioning of the Unit(s

TIME: 01.02.2013 i.e.