National Highways Authority of India Through: The Project Director, Nhai vs.reengus Sikar Expressway Ltd

Decided On : Apr-11-2019

Court : Delhi

LAW: Section 34, the ‘Act, the Concession Agreement, Concession 26.04.2011 Agreement vi Schedule 4 Lanning, the Impugned Award as Claim no.1, Article 27.1, each Annuity Payment Period, each Annuity Payment Date, this Article 27 and Article 28, each Annuity Payment Date, the Right of Way, the Concession Agreement, the Concession Agreement, Article 10.3.4 of the Concession Agreement, Section 73 and 74, the Indian Contract Act, the Contract Act, Section 74, Chapter 6 of the Contract Act, Section 74, Section 74, Section 74, Section 74, the Indian Contract Act, Section 74, the Contract Act, Section 74, the Concession Agreement, the Concession Agreement

GPE: NEW DELHI + O.M.P., Madhopur Junction, C.A., Annuity, Annuity, Annuity, Annuity, Annuity, Annuity, Annuity, Annuity, Clause, Palsana Bypass, Clause, C.A., Rs.3,24,22,683/-.30, Civil

ORG: COMM) 463/2018 & I.A. No.15416/2018 Date of Decision, NHAI, REENGUS SIKAR EXPRESSWAY LTD, JUSTICE NAVIN CHAWLA NAVIN CHAWLA, the Arbitral Award, Arbitral Tribunal, the Arbitral Tribunal, i. Authority ii Concessionaire, SPV, Total Project Cost as, Appointed Date, Concession Period, Appointed Date, Project Highway, Appointed Date, Authority, Agreement (cl.4.1.2 & Article24, Appointed Date, Authority, Schedule Project Completion Date, Effective Date of Certificate, COD Provisional, IE, Authority, Project Highway, 02.05.2104 (c/.14.3 & 15.1, Effective of, Date Provisional Certificate, COD, the Independent Engineer, COD, Annuity, the Commercial Operation Date, COD, the Scheduled Project Completion Date, COD, the Concession O.M.P., COD, Annuity, the Arbitral Tribunal, Court, Court, the Concession Agreement, Agreement, Concessionaire, COD, the Project Highway, Concessionaire, Concession, Authority, Concessionaire, Schedule M - Annuity Payment Schedule, Concessionaire, COD, Annuity, the Completion Certificate, the Clause 14.2 of this Agreement, Annuities, the Concession Period, COD, COD, COD, COD, COD, COD, Annuity, Annuity Payment, Authority, COD, The Arbitral Tribunal, Clause 27.2.2(c) & Clause, the 'Authority's, COD, COD, Claimant, COD, COD, the Arbitral Tribunal, Clause 27.2, COD, COD, COD, SPCD, SPCD, COD, SPCD, Annuity, COD, SPCD, Annuity Payment Date, Annuity Payment Date, COD, the Concession Agreement, COD, COD, Arbitral Tribunal, the Arbitral Tribunal for Clause 27.2.2 of the Agreement, the Arbitral Tribunal, Minerals Ltd., Eastern Engineering Enterprises, Nabha Power Limited, NPL, Punjab State Power Corporation Limited, Concessionaire, the Arbitral Tribunal, Arbitral, the Arbitral Tribunal, the Concession Agreement, ROW, the Statement of Claim, the Arbitral Tribunal, Project, ROW, Palsana Bypass, NH Act, Palsana Bypass, Central Government, NHAI, Authority, Appointed Date, Competent Authority, the Appointed Date, M/s Sonell Clocks, Gifts Ltd., The New India Assurance Co. Ltd., the Supreme Court, The Arbitral Tribunal, Tribunal, Arbitral, ROW Rs.2,77,38,359.00 Damages, Land/RoW, Authority/Respondent, Provisional Certificate, 3rd Annuity, the Concessionaire/Claimant, the Authority/Respondent, Kailash Nath Associates, DDA & Anr, the Supreme Court, the Arbitral Tribunal, ROW, the Arbitral Tribunal, ROW, ROW, Kailash Nath Associates, the Supreme Court, Mahanagar Telephone Nigam Ltd., TATA Communications Ltd., the Supreme Court, the Arbitral Tribunal, TPC, The Arbitral Tribunal, the Appointed Date, the Arbitral Tribunal, Clause 4.2, the Arbitral Tribunal, the Registry of this Court, Court, the Arbitral Award

CARDINAL: 11, 1, Four, 1, 2, 25.09.2014, one, 3, 14.12.2013, 14.12.2013, 27.2.1, 27.2, 27.1.1, 4, 27.2.1, 29, four, four, four, 5, 6, six, 7, 25, 14.12.2013, 14.12.2013, 29, 6, 6, 8, Four, 11, 9 Annuity, 4.2, 12, 10, 45, 4, 15, 60, 3(D, 11, 20, 9, 18, 23, 12.0, 13, 564, 22.08.2016, 4, 33, 14, 43.3, 43.6, 28, 74, 43, 43.1, 33, 12, 18, 13.11.2011, 16, 16, 16, 16, 19, 22.11.2018, 20

DATE: April, 2019, 1996, 910 days, 17 years construction period, 180 days, 132 days, 31.08.2014 xii, six months, 260 days, Eighteen, Seventy Seven, Six months, Six months, daily, months, daily, 260 days, six months, six months, daily, 7 11, six months, 1999, 2018, 8 13, 90 days, 2018, 12 22, 2nd, 2015, 1872, 1872, xxxxxx 43, 15 29, 16 32, 27.02.2019, no.14, 16, 2019

PERSON: S.Ravi Shankar, Yamunah Nachiar, Bhanu Kapoor, Dhruv Mehta, Prashant Pakhiddey, Lakshmi Dwivedi, Anubhav Ray, Cr. v, Schedule G, Max Amount, Bid, xxxxxxx iii, xxxxxxx b., Lane, Rajasthan State Mines, Anr, Anr, Claim no.7, Claim no.7, Claim no.12, Claim no.12, Claim no.12, Claim no.12, Claim no.12, Claim No.12, Claim no.12, Claim no.12, Claim no.12, no.12, Claim No.14, parties.44

NORP: cl.48.1

QUANTITY: 43.887 km, 39.532 km, 22.09.2014 xiv Amount

MONEY: 14.12.2013 O.M.P.

PERCENT: 91.07%, 90%, only 90%, 100%, only 90%, 10%, 100%

FAC: Bonus, Bonus, Bonus, 9 SCC283 ii, Sections 73 and 75, Sections 73 and 75, the Impugned Award

ORDINAL: first, first, first, first, first, first, first, 1st, first, first, first, first, first, first, first, first, 2nd, 2nd, second, third

PRODUCT: Agreement, Respondent

WORK_OF_ART: Annuity, Joint Memorandum, Rs.1,16,76,000/-.43

LOC: Respondent

EVENT: the Appointed Date, Clause 4.2

TIME: Minutes