Mapex Infrastructure Pvt. Ltd. Vs.national Highways Authority of India

Decided On : Jan-08-2018

Court : Delhi

LAW: Section 34, the Commencement Date, Article 4 of the, Article 1 (Definitions and Interpretation, Article 5.4, section 73, the Arbitration Agreement, article 5.4, article 1.1 of the agreement, section 7, section 73, the Contract Act.91, the Concession Agreement, the Concession Agreement, Section 73, the Contract Act, Article 19.3, the Concession Agreement, Article 19.3(the ‘Indemnified Party, the Concession Agreement, Article 8.3, Section 73, the Contract Act, Article 8.3, each Annuity Payment Period, Article 7, Article 3.2(d, Article No.8.3 of Concession Agreement Description Period Time Proportionat, Section 34, section 73, the Contract Act, section 73, the Contract Act, the Concession Agreement, section 73, the Contract Act 1872, Article 1 defines, Article 4, article 5 and 9, Section 34

GPE: NEW DELHI, Panagarh, the State of West Bengal, payment.10, no.7, no.7, no.3, damages.30, Bonus, Reduction, Annuity, Scope, Q58, rejected.46, p.a.

DATE: November, 2017, January, 2018, 1996, 17th March, 2015, September 2001, 21st November, a period of, 17 years, 6 months, 21st June, 2002, 20th December, 2019, 21st June, 2002, 20th December, 2 2004, 9th June, 2005, 171 days, 28th December, 2006, 3rd January, 2007, 8th June, 17th March, 2015, 2015, 3 3, 10.6.2005, 36,963,258/-, August, 2004 to 9th June, 2005, under Section 73, 1996, 17th April, 2017, 8th November, 2017, 1993, 8 17, 2015, two months, 2 months, a period of, two months, six months, 2017, fourteen) days, 14 25, 171 days, 29th June, 2005, 8th June, 2007, days, 171 days, 29th June, 2005, days, Days, 03 1, 15/64.457)*29=6.75 129, Days 70, June 2005, 2005, 171 days, 2017, 21st December 2004 to 9th June 2005, December 2004 to June 2005, August 2004 to 9th June 2005, 21st December 2004 to 9th June 2005, 171 days, 08.06.2007, yearly, monthly, two or three months per year, that month, monthly, two or three months, that month, a month, 3 years, a particular month, monthly, the year I picked months, monthly, monthly, a specific month, 25 43, 171 days, 06-2005, 47, JANUARY8 2018

PERSON: Arun K. Varma, S.K. Chandwani, Ashish Joshi, Sameer Chandwani, Gunjan S. Jain, Gunjan S. Jain, Arun K. Varma, S.K. Chandwani, Ashish Joshi, Sameer Chandwani, Vehicle, Award, Award, Claim No.8, Claim, Claim No.7 Rs, Claim No.8, Award Rs nil, Mohanlal Harbans Lal Bhayana, McAlpine, McAlpine, Keith, S. L. T. 533, McAlpine, McAlpine, McAlpine, McAlpine, Concessionaire, Nos, Shaktigarh Bypass Km, Change Scope, Person, Schedule, interalia, Philip E.Konen, Q56, no.8, Nos, no.8

ORG: NATIONAL HIGHWAYS AUTHORITY OF INDIA Through, JUSTICE NAVIN CHAWLA OMP Nos.384 & 391/2015 Page 1 1, Arbitral Tribunal, Infrastructure Pvt. Ltd., National Highways Authority of India, Palsit, NHAI, Letter of Acceptance No., the Consortium of M/s Gamuda-WCT Joint, NHAI, Build, Operate and Transfer (, BOT, Commencement Date, Concessionaire, the Commercial Operation Date, COD, the Scheduled Project Completion Date, OMP Nos.384 & 391/2015, the Independent Engineer, COD, NHAI, NHAI, Project, IE, IE, the Arbitral Tribunal, Arbitrators Amounts Awarded, Bonus for Early Completion: Rs, EPC Contractor’s Time-related, OMP No.391 of, OMP Nos.384 & 391/2015, Concessionaire, Delay & Disruption Nil Nil, EPC Contractor, Arbitrators, Change, Arbitrators Interest, Claims No.2 & 6, OMP Nos.384 & 391/2015, 9.11.2008 Interest, OMP Nos.384 & 391/2015 Page 5 11, no.2, the Concession Agreement, EPC Contractor, NHAI, EPC, the EPC Contractor, the Arbitral Tribunal, EPC Contractor, Claimant, OMP Nos.384 & 391/2015 Page 6, EPC, EPC, EPC, EPC, EPC, EPC, EPC, the Arbitral Tribunal, EPC Contractor, EPC Contractor, Court, OMP, Court, OMP Nos.384 & 391/2015 Page 7, EPC Contractor, the Arbitral Tribunal, Court, FAO(OS, House of Lords, Linden Gardens Trust Ltd., Lenseta Sludge Disposals Ltd. & Ors, the EPC Contractor, Arbitrators, EPC Contractor, The Arbitral Tribunal, EPC Contractor, the Arbitral Tribunal, EPC, EPC Contractor, OMP Nos.384 & 391/2015, the Arbitral Tribunal, EPC, EPC, Concessionaire, Concessionaire, Larsen & Toubro Ltd., the Supreme Court, the High Court, SCOPE, SCOPE, SCOPE, SCOPE, SCOPE, SCOPE, Arbitral Tribunal, SCOPE, OMP Nos.384 & 391/2015 Page 9, Arbitral Tribunal, Arbitral Tribunal, the Arbitral Tribunal, the EPC Contractor, EPC, the EPC Contractor, EPC Contractor, the Arbitral Tribunal, EPC Contractor, the Arbitral Tribunal, EPC Contractor, IE, EPC Contractor, the OMP Nos.384 & 391/2015 Page 10 EPC Contractor, Sharma and Associates Contractors Pvt. Ltd., Progressive Constructions Ltd., SCC743 Supreme Court, an Arbitral Award, the Principal Contract, the Principal Contract, the Arbitral Tribunal, EPC, Arbitral, Linden Gardens Trust Co., the House of Lords, the third party, the House of Lords, The House of Lords, Corporation, Corporation, Investments OMP Nos.384 & 391/2015 Page 11, Corporation, Corporation, Corporation, Littlewoods Mail Order Stores Ltd., Corporation, Corporation, Corporation, McAlpine, Corporation, the House of Lords, the EPC Contractor, EPC Contractor, NHAI, OMP Nos.384 & 391/2015 Page 13, a Political Event, Concessionaire, NHAI, NHAI, Party, Party, the Indemnifying Party, the Indemnifying Party, the Indemnified Party, the Indemnified Party, the Arbitral Tribunal, EPC Contractor, the Arbitral Tribunal, Arbitral Tribunal, OMP Nos.384 & 391/2015, EPC Contractor, the EPC Contractor, the EPC Contractor, EPC Contractor, the Arbitral Tribunal, EPC Contractor, NHAI, OMP, NHAI, Concessionare, the Arbitral Tribunal, IE, OMP Nos.384 & 391/2015 Page 15, the Arbitral Tribunal, IE, NHAI, the Concession Agreement, below:-""8.3 Bonus/Reduction in Annuity, the Project (the Bonus, Annuity, the Project (the Reduction, COD, OMP Nos.384 & 391/2015 Page 16 (ii, COD, Previous Annuity Payment Date, Reduction Scheduled Project Completion Date, Engineer, the Project Site, NHAI, Construction Works, the Independent Engineer, Concessionaire, the Construction Works, Concessionaire, Project Site, a Political Event or Other Event, OMP Nos.384 & 391/2015 Page 17, Concessionaire, COD, NHAI, COD, The Arbitral Tribunal, The Arbitral Tribunal, NHAI, the Whole Project, OMP Nos.384 & 391/2015, Km, Km, Km, Km, Court, OMP Nos.384 & 391/2015 Page 19, the Objection Petition, NHAI, NHAI, the Schedule Date of Completion, Concessionaire, NHAI, NHAI, Assam State Electricity Board And Ors, Buildworth Pvt. Ltd., SCC146 Supreme Court, NHAI, Arbitral, the Arbitral Tribunal, NHAI, merit.38, IE, The Arbitral Tribunal, under:-""163, the OMP Nos.384 & 391/2015 Page 21, IE, IE, Schedule L, IE, IE, IE, EPC, no.2, Concessionaire, IE, SOC, The Arbitral Tribunal, IE, Court, Independent Engineer, under:-"OMP Nos.384 & 391/2015 Page, Independent Engineer, Concessionaire, the Project Requirements, Schedule, Good Industry Practice, the Construction Requirements, Independent Engineer, xxxxxx (viii, Change, Law and/or Change, the Independent Engineer, IE, IE, the Arbitral Tribunal, OMP Nos.384 & 391/2015 Page 23, IE, the EPC Contractor’s, EPC, Concessionaire, EPC, EPC, EPC, OMP Nos.384 & 391/2015 Page 24 Q46, EPC, Concessionaire, Concessionaire, Concessionaire, Concessionaire, EPC, Q57, OMP Nos.384 & 391/2015 Page, the Arbitral Tribunal, IE, the Arbitral Tribunal, the Arbitral Tribunal, Court, the Arbitral Tribunal, Court, NHAI, The Arbitral Tribunal, no.1, OMP Nos.384 & 391/2015 Page 26, BOT, The Arbitral Tribunal, OMP Nos.384 & 391/2015 Page 27

CARDINAL: three, Four, 26, 2001.5, 2007.8, 2015.9, 1.2, 379,281,932/-, 4, 214,542,785/, 4, 122,634,977/, 8, 17,26,991/-, 31,151,661/-, No.1 to 9, 10, 90, 15, 3, three, 2, 1, 19.2, 19.3, 3-3-1998, 19.4, 18, 5, 538, 12, 22, a third, 14, 24, one, 2, 6, 180, two, 32, 45.83, 5.92/64.457)*499=45, 02, 18, 579, 542 + 000, 557 + 000, 539 + 000, 542, 522, 526, 02, Mar-02, 02, 490 33.07, 14, 14, 14.6, NHAI.34, 8.3, 8, 20, 2.2, four, 302, 2,3,4, 5, 171/302=0.566, 6, 328, 39, 22, 41, 2.2(a)(viii, 42, No.3, 08.06.2007, 102, 103, 163, 164, 9, No.7, 6, 1, 6

WORK_OF_ART: Strengthening of Existing Two Lane Pavement of National Highway No.2, Deferred Payment for Changes of Scope and Additional Works: Rs, Indemnifying Party, Award under Section 34 of the Act

PERCENT: 12%, 12%, 12%, 13.5%, 12%, 12%

ORDINAL: first, 11th, first, third, third, third, third, first, first, first, first, second, 11th

PRODUCT: F2, MAPEX.23, Agreement, Chartered Accountant, Q44, Q56, No.1

FAC: Bonus, Bonus, OMP no.391/2015

EVENT: 9 69.5 33